Decisions of the Department of the Interior, Volum 63U.S. Government Printing Office, 1956 |
Inni boken
Resultat 1-5 av 100
Side 1
... Contractor - Con- tracts : Damages : Liquidated Damages Where the contractor , who was engaged in the installation of a curtain in the Carter Barron Amphitheater in Rock Creek Park , Washington , D. C. , ac- cepted a change order which ...
... Contractor - Con- tracts : Damages : Liquidated Damages Where the contractor , who was engaged in the installation of a curtain in the Carter Barron Amphitheater in Rock Creek Park , Washington , D. C. , ac- cepted a change order which ...
Side 2
... contractor to prepare working drawings , covering all phases of the installation , and these drawings were to be submitted by the contractor to the con- tracting officer for approval before proceeding with the work . The Carter Barron ...
... contractor to prepare working drawings , covering all phases of the installation , and these drawings were to be submitted by the contractor to the con- tracting officer for approval before proceeding with the work . The Carter Barron ...
Side 3
... contractor that he was unduly delaying the work , and warned him that such delays might lead to the assessment of liquidated damages . Complaint was made in particular of the failure of the contractor to submit the necessary shop ...
... contractor that he was unduly delaying the work , and warned him that such delays might lead to the assessment of liquidated damages . Complaint was made in particular of the failure of the contractor to submit the necessary shop ...
Side 6
... contracting officer might have granted a longer extension of time than the contractor accepted , and acted upon the assumption that a change order could not be issued unless it included a definite time extension , or stated that no ...
... contracting officer might have granted a longer extension of time than the contractor accepted , and acted upon the assumption that a change order could not be issued unless it included a definite time extension , or stated that no ...
Side 7
... contractor to notify the contracting officer of a cause of delay within 10 days of its commencement . It is clear that the letter of June 9 , 1954 , which was written by the contractor after the acceptance of the work performed under ...
... contractor to notify the contracting officer of a cause of delay within 10 days of its commencement . It is clear that the letter of June 9 , 1954 , which was written by the contractor after the acceptance of the work performed under ...
Andre utgaver - Vis alle
Decisions of the Department of the Interior, Volum 63 United States. Department of the Interior Uten tilgangsbegrensning - 1956 |
Decisions of the Department of the Interior, Volum 63 United States. Department of the Interior Uten tilgangsbegrensning - 1956 |
Decisions of the Department of the Interior United States. Department of the Interior Uten tilgangsbegrensning - 1957 |
Vanlige uttrykk og setninger
acreage acres additional compensation adjacent danger tree administrative Administrative Procedure Act Alaska Alaska Railroad amended appellant's application August August 17 August 28 Board Bureau of Land canal canceled change order claim coal conflict construction contest contracting officer contractor danger tree strips delay Department determination Director Director's decision entitled entry excavation extension fact filed gas lease Government grazing hearing held Helmick homestead Indian Interior sec issued January January 23 July July 29 June June 11 known geologic structure Land Management land office Larsen lease offers lessee liquidated damages ment Mineral Leasing Act Northern Pacific November October offeror oil and gas oil or gas operations overruled paragraph patent period permit preference right prior provisions public land pursuant record regulation rejected reservation right-of-way ruled Secretary shale Shallit Soap Lake Solicitor special tracts specifications Stat Taylor Grazing Act timber tion tribal tribe United Usibelli Yakutat
Populære avsnitt
Side 94 - Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his decision to writing and mail or otherwise furnish a copy thereof to the Contractor.
Side 276 - In instances in which private persons are the moving parties, other parties to the proceeding shall give prompt notice of issues controverted in fact or law; and in other instances agencies may by rule require responsive pleading. In fixing the times and places for hearings, due regard shall be had for the convenience and necessity of the parties or their representatives.
Side 348 - By EO 5327, Apr. 15, 1930, made under authority and pursuant to the provisions of the act of June 25, 1910 (36 Stat.
Side 54 - That the Secretary of the Interior is authorized to prescribe necessary and proper rules and regulations and to do any and all things necessary to carry out and accomplish the purposes of this act...
Side 54 - ... substantive rules adopted as authorized by law and statements of general policy or interpretations formulated and adopted by the agency for the guidance of the public, but not rules addressed to and served upon named persons in accordance with law.
Side 196 - Act, and the treatment and shipment of the products thereof by or under authority of the Government, its lessees, or permittees, and for other public purposes...
Side 42 - Reserve, shall have a preferred right of entry under the homestead or desert land laws, if qualified thereunder, except as against prior existing valid settlement rights and...
Side 292 - Officer in writing of: (1) subsurface or latent physical conditions at the site differing materially from those indicated in this contract, or (2) unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in this contract.
Side 61 - Alaska and as prescribed in the lease. (b) On leases wholly or partly within the known geologic structure of a producing oil and gas field...
Side 197 - States the right to lease, sell, or otherwise dispose of the surface of the lands embraced within such lease under existing law or laws hereafter enacted, In so far as said surface is not necessary for use of the lessee in extracting and removing the deposits therein : Provided further, That if such reservation is made it shall be so determined before the offering of such lease.